20 19 house renovation contract and budget sheet house decoration process and matters needing attention.

You must find a professional decoration company for house decoration. Before determining the construction of the decoration company, we must sign the renovation contract and the budget. The house should be clear that the contract is valid and legal after being sealed, and the construction process should be carried out according to the construction plan. Any problem will be protected by law, and rights and interests will be safeguarded by law. It is very important for users to choose a formal decoration company to decorate their houses. Let's take a look at the house decoration process and matters needing attention.

I. 20 19 Housing renovation contract and Budget Table

(1) House renovation contract

Customer (Party A):

Organizer (Party B):

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, this contract is hereby signed in accordance with relevant national laws and regulations for * * * * to abide by.

Article: Project overview

1, project: _ _ _ _.

2. Room specification: room type, with a total construction area of square meters.

3. Construction content: See Annex (1) List of Home Decoration Construction Contents and Construction Drawings for details.

4. Entrustment: contracting materials and turnkey projects of materials.

5. Commencement date: April, XX 15, completion date: June, XX 14, and total project days: 60 days.

Article 2: Project Price

The project price (in words) is shown in Annex (II) Budget Table of Home Decoration Engineering Materials.

Article 3: Quality Requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties.

2. The acceptance standard of this project shall be implemented with reference to the relevant provisions of the state.

3. In the process of construction, if Party A has special construction projects or special quality requirements, both parties shall sign a supplementary contract for the increased cost.

4. Party A shall be responsible for the quality of all materials and equipment purchased by it; Party B shall be responsible for the quality of the project.

5. If Party A hires a project supervisor, it shall notify Party B before the project starts, so as to facilitate the work connection.

Article 4: Supply of Materials

1. Party B shall clearly price the materials used in this contract in strict accordance with the relevant national price regulations. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.

2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall be prohibited from being used. If it has been used, all losses caused to the project shall be borne by Party B. ..

3. The materials and equipment that Party A is responsible for purchasing and supplying shall be qualified products that meet the design requirements, and shall be supplied to the site on time. Delayed arrival, postponed construction period and delayed punishment. Pay Party B 10% of the total materials provided by Party A as the management fee. After the materials are accepted by Party B, Party B shall be responsible for keeping them, and Party B shall be responsible for compensating the losses caused by improper keeping.

Article 5: Payment

1. After the contract is signed, Party A shall pay 50% of the engineering materials and engineering expenses; When the time limit for a project is over half (May 25th, XX), Party A will pay 40% of the project payment for the second time. The remaining 10% shall be paid to Party A after the project is completed and accepted. (Note: Construction costs include labor costs).

2. Party A's failure to pay on time is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.

Article 6: Construction Period

1. If the completion is delayed due to Party B's reasons, Party B shall pay Party A 1% of the working expenses as liquidated damages every day until the working expenses are deducted. If the completion is delayed due to Party A's reasons, Party B shall be paid 1% of the labor cost in the decoration project price for each day of delay.

2. If the unqualified materials and equipment selected by Party A affect the project quality and time limit for a project, Party A shall bear the cost of rework, and Party B shall bear the cost of rework for quality accidents caused by Party B's construction, and the time limit for a project remains unchanged.

3. During the construction, due to the quality problems of the project, both parties disagree, resulting in the suspension of work, failure to act as punishment for delaying the work or the construction period. Both parties should take the initiative to ask the relevant departments to mediate or the arbitration department to coordinate and deal with the dispute as soon as possible, so as to continue the construction.

Article 7: Other matters

1, Party A's responsibility

1) The house plan and water, electricity and gas circuit diagram approved by the property management department must be provided, or Party A shall provide the house plan and water, electricity and gas circuit diagram, and make on-site disclosure to Party B. ..

2) Secondary decoration project, in which all or part of the house is vacated and obstacles affecting the construction are removed. Necessary protective measures shall be taken for furniture and furnishings that can only be partially vacated in the house, and all formalities shall be handled with Party B, and the expenses shall be borne by Party B..

2. Party B's responsibilities

1) Assign a staff member as the on-site representative of Party B to be responsible for the performance of the contract, organize the construction according to the contract requirements, and complete the construction task on time with good quality and quantity.

2) Be responsible for the safety, fire prevention and civilized construction of the construction site, so as to prevent accidents such as pipeline blockage, water leakage, power failure and damage to articles caused by construction from affecting others. If it happens, it must be repaired or compensated as soon as possible.

Article 8: Liability for breach of contract

After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay the other party 5% of the total contract amount as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.

Article 9: Settlement of disputes

In case of any dispute during the performance of this contract, both parties shall settle it through consultation without affecting the project progress. If the parties are unwilling to settle the dispute through consultation, or if consultation fails, they may bring a lawsuit to the people's court in accordance with the contract.

Article 10: Modification and Termination of the Contract

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, and pay a penalty of 65,438+00% of the total contract price, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.

Article 11: Entry into force of the contract

1. This contract shall come into effect after being sealed by both parties.

2. This contract is made in duplicate, with each party holding one copy.

Party A (Owner): Party B:

Signature: customer signature:

Date of signing: Date of signing:

(b) Housing renovation budget

1, paperback 80,000

With a budget of 80,000 yuan 1.20 square meters, users with financial difficulties can simply move in and get their daily needs in the newly renovated house. Decoration works include: kitchen and bathroom, water and electricity, floor, wall, balcony and top surface.

2, at 654.38+ million.

The house decorated with 65438+100000 yuan is still good. For the house with 120 square meters, the quality of the selected decoration materials and styles is still guaranteed. When designers design the decoration style, there are many design elements, and the decoration effect and quality are also very good. Decoration works include: floor, wall, top, water and electricity, balcony, kitchen and bathroom.

3. Hardcover 1.5 million

There are quite a few people who choose fine decoration for the main decoration of the house. These people are people who pursue high-quality life, so they want their living space to be exquisite and gorgeous. Buy some medium-quality decoration materials and find a brand decoration company to decorate your house. 1.8 million yuan decoration, which is luxurious enough.

Note: This price source network is for reference only! Due to different regions, the quotation of decoration materials and decoration companies will be different. For more information about decoration materials and budget quotation, please consult local decoration material dealers and decoration companies! The designer will give a reasonable decoration according to the user's decoration.

Budget quotation

!

Second, the housing renovation process and matters needing attention

(A) Housing renovation process

1, preliminary design

The preliminary design of house decoration is very important. Many users pay special attention to whether the decoration company is formal when decorating the house. A regular decoration company has a professional design team, which will be professional in design and novel in design style. The effect and quality of the renovated house will be good.

2. Demolition and transformation of the main body

The demolition and reconstruction of the main body is an important project in the process of house decoration. Professional designers make a framework for house decoration, and then carry out construction and decoration according to the plan.

3. Details conversion

When the construction framework comes out, the construction personnel can carry out the transformation of the ground, wall, top surface and water and electricity, and decorate the places that need construction indoors, paying attention to the details of house decoration and ensuring the decoration quality of the house.

4. Kitchen, doors and floors

Installation of kitchen and bathroom ceiling, cabinets and wooden doors. The owner must supervise the installation details. Ensure the installation quality of ceiling, cupboard and wooden door, which can be used normally.

5. Install radiators, lamps and sanitary ware.

This part needs to be drilled into the wall or shed. This part is relatively simple. You can arrange it yourself if you like. When these devices are completed, you will find that you really feel a little at home.

6, all kinds of furniture, electrical appliances comes into play

After the house is decorated, furniture and electrical appliances can enter the venue. The style of furniture depends on what style the owner likes, both European and Chinese can be used.

(2) Matters needing attention in house decoration

1, kitchen decoration

When decorating a house, everyone must pay attention to the kitchen decoration, and try to close the kitchen as much as possible, so as to avoid kitchen fumes from affecting other rooms, affecting the health of indoor users for a long time and causing indoor air pollution.

2, the bathroom waterproof

Be sure to pay attention to the waterproof company before the renovation of the bathroom to avoid problems in the use of the bathroom. To choose good quality sanitary ware, choose practical and easy to clean. Especially the washbasin and bathtub in the bathroom should be easy to clean.

3. Bedroom color

The bedroom should choose the color that users like, and should not be decorated blindly, otherwise it will affect the sleep quality of users. Choosing warm colors for lighting will not irritate the eyes, save energy and protect the environment, and will make the bedroom more warm and comfortable.

4. Ground materials

The floor material for new house decoration is very important. Common materials are ceramic tiles and wood floors, while the floors of living room, kitchen and bathroom are all ceramic tiles, which are not only wear-resistant, but also convenient and clean.

Third, how to save money in house decoration

1, keep a material account.

When the house is being renovated, you must go to the store to buy it, shop around, choose affordable decoration materials, then let the decoration company write a detailed material quotation to see if the decoration company has cut corners, and finally negotiate with the decoration company.

2. Make a good design account.

If you want to decorate the house economically and practically, you must find a professional designer, divide the various areas of the house by the designer, meet the design needs of users, and carry out construction design and decoration through design drawings.

3. Choose a good decoration company

Choose a regular and reliable decoration company for design, planning and construction to ensure the quality of house decoration and one-stop service for house decoration.

4. Simple suspended ceiling

Don't make a complicated ceiling on the ceiling, try to hide the lights inside. This will not only save you decoration costs, but also make the indoor space more beautiful. What we need is to make the ceiling simple and high enough to stretch the living space.

Fourth, how to check and accept the house decoration?

1, circuit acceptance

When decorating a house, we must do a good job in circuit acceptance, make the circuit paving smooth and firm, and do a good job in circuit wiring. Air ducts should be installed on the line crossing the wall, and the air ducts should be closely connected. If the lines are connected by aluminum wires, splicing or binding methods cannot be used. When using pipeline wiring, the connection points need to be tight and reliable, so that the pipeline structure and electricity are integrated and there is reliable grounding.

2. Acceptance of doors and windows

The overall quality of the house, including whether there are cracks in doors, windows, balconies and other parts. One more question. Because the newly renovated house needs ventilation and is closed for a long time, dust and construction waste will inevitably appear on the door and window tracks. So check these places carefully before opening them, and clean them in time if there is a foreign body feeling.

3, drainage acceptance

If it is a high-rise building, it is necessary to check the drainage of balcony and roof, whether the installation of drain, gutter and downpipe is firm, and whether the interface is flat and dense.

4. Ground acceptance

Let's see if the relative elevation of the bathroom, balcony, bathroom floor and adjacent floors meets the requirements, and there can be no water accumulation, flooding or leakage. All floors should be smooth and firm, and the joints should be tight.

The above is about the renovation contract of 20 19 house, budget list, house decoration process and matters needing attention. I hope it will help everyone!