5 housing construction contract

The purpose of a contract refers to the purpose that the parties to the contract ultimately expect or achieve through the conclusion and performance of the contract. The following is the housing construction contract I carefully arranged for you, I hope you like it!

House construction contract 1

Housing construction party (Party A):

Contractor (Party B):

Through friendly negotiation between Party A and Party B, Party A contracts the homestead housing construction project located in Xiajiawan, He Qiao Village, Jinniu Town, daye city to Party B, and both parties sign this contract on the principle of equality, voluntariness, honesty and credit, and hope that * * * will abide by it together.

First, the contracting method.

The construction project adopts the method of clearing the package, that is, the contractor does not package the materials.

Second, the construction period

This project started on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Demolition of the old: _ _ _ _ _ _ _

Graduation ceremony: _ _ _ _ _ _

Tighten the beam: _ _ _ _ _ _ _

Completion time: _ _ _ _ _ _ _ _

If the planned construction progress cannot be achieved due to the delay of the project, Party B shall pay a penalty of RMB Yuan to Party A for each day of delay.

Three. Party A's responsibilities

According to the needs of building construction, Party A shall provide the required building materials such as cement, steel bars, bricks and sand in time to ensure the smooth construction of Party B within the agreed time limit, and Party B may make guiding suggestions on the quality and price of the purchased materials.

Four. Party B's responsibilities

Party B shall provide all construction tools, such as templates, mixers, vibrators, scaffolding and concrete mixers. (The freight shall be borne by Party B) and construction personnel such as masters and coolies shall carry out the construction according to the drawings provided by Party A or Party A's requirements, and put forward reasonable suggestions and opinions from a professional perspective.

(1) Contract scope:

1, main building project

Party B is responsible for the construction (including balcony, stairs, windows, septic tanks and other necessary parts) from Party A's pouring of foundation beams to roof capping. Vibrators should be used to water floors, floors and horizontal surfaces as needed.

2. In addition to the main structure of the house, Party B shall also be responsible for the following contents.

(1) Laying of water, electricity and gas pipelines, lines and corresponding supporting facilities (hydropower part)

(2) Exterior walls, kitchens, bathrooms and roofs should be waterproof.

(3) Tile or granite on the ground, porcelain-sticking works such as toilet decoration, etc.

(4) Installation of stair railings and balconies of other ancillary facilities of the house

(5) Other equipment to be installed shall be installed by the Seller, otherwise Party B shall be responsible for the installation.

(2) Engineering quality requirements:

1. The wall-building plane should be flat and vertical, with vertical vertex angle, full mortar, smooth and firm watering, smooth and flat white wall, flat and tidy wall tiles, reasonable gaps, and steel bars and binding steel bars should meet the requirements of the drawings. One layer of internal wall cement slurry and two layers of external wall cement slurry.

2. The circuit shall be constructed according to the drawings, with reasonable, standardized and safe layout; Switches and sockets are arranged reasonably and can be used normally.

3. Water pipes and drainage pipes shall be designed according to the drawings or constructed according to the requirements of Party A. ..

Party B shall be responsible for the losses caused by the unqualified quality of the above projects.

V. Engineering Inspection and Acceptance

Without affecting the normal operation of Party B, Party A shall supervise and inspect the progress and quality of the project and accept it within one month after the completion of the project construction.

Six, the project payment calculation method

The main project of the house shall be calculated according to the actual construction area from the time of bricklaying, and calculated according to the 220 yuan contract fee per square meter (the height of half-story cornice shall be negotiated by both parties). The calculation method is as follows: the first floor is measured according to the actual building area, starting from the center line of the external wall; The second floor is calculated according to the measured area of the first floor plus the balcony area.

Man-hours for laying foundation and watering ground fiber beams and sites are calculated at the market price of RMB yuan per day; The porcelain pasting part is calculated at the market price of _ _ yuan/day.

Seven, the project payment method

The project payment shall be settled after completion, and 50% of the total project payment shall be paid after the successful completion of the house construction, 30% after the completion of the project, and three months after the house quality inspection is qualified.

20%。

Eight, quality assurance obligations

Party B shall ensure that the quality of the house built is reliable. If the house has slight quality problems such as water leakage and cracks within one year due to Party B's construction, Party B shall provide it free of charge within one year. Ruzai

In case of serious quality problems such as foundation sinking caused by construction within one year, Party B shall rework and rebuild for free.

Nine, safety responsibility

Party B must seriously abide by the construction operation rules, bring safety facilities such as scaffolding, safety belts and helmets, do a good job in safety education for construction personnel, and insist on safety first and quality first.

First, give priority to prevention. In case of any safety accident during construction, Party B shall be responsible, and Party A shall not bear any responsibility.

X. other unfinished business.

1. Party A and Party B shall be responsible for keeping their own materials and tools.

2. On the premise of ensuring the quality, Party B shall take good care of the materials and avoid wasting them.

3. This agreement is made in duplicate, with the same legal effect, and shall come into force after being signed by both parties. If there is any problem in the construction, both parties shall make changes through consultation. Both parties shall earnestly perform this Agreement, and the losses caused by Shang Ruo's breach shall be borne by the breaching party.

4. Matters not covered shall be settled by both parties through negotiation. If negotiation fails, it shall be implemented in accordance with People's Republic of China (PRC) Contract Law and other relevant laws and regulations. Any dispute between Party A and Party B shall be settled through friendly negotiation first. If negotiation fails, either party may bring a lawsuit to the court.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Housing construction contract ii

Construction Contract (Party A):

Contractor (Party B):

Through friendly negotiation between Party A and Party B, Party A has awarded the lighting project of private houses in Maotai Town, renhuai city, Guizhou Province to Party B, and both parties have signed this contract on the principle of equality, voluntariness, honesty and credit, and hope that * * * will abide by it together:

First, the contracting method.

The construction project adopts the method of clearing the package, that is, the contractor does not package the materials.

Second, the construction period, contract scope and project payment calculation method

The construction of this project shall be calculated from the date when Party B enters the site, and the construction period shall be completed before May 15, 20__, and Party B shall guarantee to complete the construction progress within the specified time. Details of contracted projects are as follows:

1. Party A only provides building materials to the roadside of the construction site, and Party B is responsible for the handling and use of building raw materials.

2. Bricklaying is calculated according to the number of blocks, and the unit price is 0.55 yuan/block (0.55 yuan/block); The unit price of exterior wall brick is: 58 yuan per square meter, (58 yuan/㎡).

3. Party B must complete the above-mentioned 1 to 2 contracted projects within the specified time. If it is not completed within the specified time, Party A will not pay Party B any project funds, and Party B will compensate Party A for the losses caused by the delay in the construction period.

Three. Party A's responsibilities

According to the demand of housing construction, Party A shall provide the building materials needed for housing construction in time to ensure the smooth construction of Party B within the agreed time limit.

Four. Party B's responsibilities

Party B shall bring its own tools for building walls and external wall tiles (the freight shall be borne by Party B) and construction personnel such as foremen and coolies, and carry out the construction according to the drawings provided by Party A or Party A's requirements.

Five, the engineering quality requirements

The wall-building plane should be flat, with vertical corners and vertical top corners, full mortar, smooth and firm surface, neat external wall bricks and reasonable gaps. Party B shall be responsible for the losses caused by the unqualified acceptance of the above engineering quality.

V. Engineering Inspection and Acceptance

Under the condition that the normal operation of Party B is not affected, Party A shall supervise and inspect the progress and quality of the project. After the project construction is completed, Party B shall notify Party A for acceptance, and pay the project payment after it is qualified.

Six, the project payment method

The project payment is paid in two parts. After the house starts 10, Party A guarantees to pay the living expenses for the house construction of Party B.. After the project is completed and accepted, Party A shall pay Party B the housing construction cost in one lump sum.

Seven, safety responsibility

Party B must seriously abide by the construction operation rules, wear the scaffolding, safety belts, safety helmets and other safety facilities provided by Party A, do a good job in safety education for construction personnel, and insist on safety first, quality first and prevention first. In case of any safety accident during construction, Party B shall be responsible, and Party A shall not bear any responsibility.

Nine. Other information

During the construction period, Party B will take care of himself, and Party A will only provide housing.

X. other unfinished business.

1. Party A and Party B shall be responsible for keeping their own materials and tools.

2. On the premise of ensuring the quality, Party B shall take good care of the materials and avoid wasting them.

3. This agreement is made in duplicate, with the same legal effect, and shall come into force after being signed by both parties. If there is any problem in the construction, both parties shall make changes through consultation. Both parties shall earnestly perform this Agreement, and the losses caused by Shang Ruo's breach shall be borne by the breaching party.

4. Matters not covered shall be settled by both parties through negotiation. If negotiation fails, it shall be implemented in accordance with People's Republic of China (PRC) Contract Law and other relevant laws and regulations. Any dispute between Party A and Party B shall be settled through friendly negotiation first. If negotiation fails, either party may bring a lawsuit to the court.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Housing construction contract 3

Lessor: _ _ _ _ _ _ (hereinafter referred to as Party A)

Lessee: _ _ _ _ _ _ (hereinafter referred to as Party B)

According to the Contract Law and the regulations of the state and local governments on house leasing, the following agreement is reached on house leasing through friendly negotiation between both parties.

1. The leased house is located at. # # # Lane # # Village # # Yongxing Street, Longwan, Wenzhou City, two three-story floor-to-ceiling houses and their ancillary equipment are rented out to the lessee for residential use.

2. The lease period starts on May 20th 19 in the Gregorian calendar and ends on May 19 in the Gregorian calendar.

3. The rent is calculated on an annual basis, and the annual rent is RMB 20,000.00 Yuan, which shall be paid by the lessee to the lessor in one lump sum on the 20th day of the solar calendar.

4. The water, electricity and cable TV fees shall be paid in advance by the lessor #, and then charged to the lessee # according to the actual amount of water and electricity each month. Cable TV charges from May 20th to May 20th will be charged on1October 20th. As for how to share the cost of water, electricity and cable TV for each household in the rented house, the lessee will negotiate with each household and pay the same fee.

Five, the lessee should take good care of the leased house, damage or improper use caused by the destruction of the house, to be liable for compensation; If the lessor changes the use function of the house and needs to change the structure of the leased house for decoration or add or transform ancillary facilities, it shall obtain the consent of the lessor and the required funds shall be borne by the lessee. If the lease relationship changes, the decoration will not make any compensation.

Six, the lessee should consciously do a good job in fire prevention, theft prevention and safety, such as fire prevention, theft prevention and safety problems, resulting in personal and property losses to the lessee, the lessee shall bear all the responsibilities, resulting in property losses to the lessor shall be liable for compensation.

7. After the signing of this contract, the lessor and the lessee must fully perform it. Without the consent of the other party, neither party may change or terminate the contract without authorization. If either the lessor or the lessee violates this contract and liquidates the actual rent, it shall pay the other party a penalty of 65,438+00% of the total annual rent. However, if the lessee is noisy, quarreling and other uncivilized behaviors that affect the neighbor's life, the lessor can immediately take back the rented room without paying liquidated damages.

Eight, the lessee should handle the relationship with neighbors, keep indoor, outdoor and public places clean and hygienic, do not raise animals, do not make noise at night, and do not affect neighbors' rest at night.

Nine. Matters not covered in this contract shall be settled by both parties through consultation in the spirit of mutual understanding and accommodation.

This contract is made in duplicate, one for each party.

After the rent is paid, both parties sign this contract for confirmation:

Opinion: The above-mentioned rent of 20,000 yuan will be paid on _ _ _ _ _ _ _ _ _ _ _ _ _.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Housing construction contract 4

Employer: Group 1, Reduidougou Village, Xuanwei City (hereinafter referred to as Party A) Legal Representative: Zhao Jihai.

Contractor: (hereinafter referred to as Party B) According to the provisions of the Contract Law, General Principles of the Civil Law and other relevant laws and regulations, Party B contracted the 1 street pavement opposite the village committee of Gegougou Village, Reshui Town, which belongs to Party A, to operate. In order to facilitate the timely and comprehensive performance of this contract by both parties, this contract is made on the principles of equality, voluntariness, consensus and mutual benefit, and both parties are expected to abide by it.

Article 1 Name of contract.

There is a street opposite Dougou Village Committee in Reshui Town, Xuanwei City.

Article 2 Term of Contract >

& gt

& lt the first anniversary, from 65438+1October 2 1 to 65438+1October 2/20__.

Article 3 Contract expenses

* * * yuan).

Article 4 Payment of Contract Fees

One-time payment, 20 _ _-65438+ years1October 5, one-time payment of the contract fee, and sign and seal this contract.

Article 5 Rights and Obligations of Party B

1. Use the contract house as agreed.

2. Pay the contract fee and electricity fee on time.

3. In order to maintain the Contract House, the structure of the Contract House shall not be changed without the written consent of Party A. ..

4, according to the law, shall not engage in illegal activities.

5. Party A is not responsible for handling and paying relevant taxes and fees in relevant departments such as industry and commerce, taxation and urban construction.

6. Manage fire prevention, theft prevention and personal safety by itself, and be responsible for any loss, and Party A will not be responsible.

7. When the Contract House expires, Party B will unconditionally return the Contract House to Party A. ..

8. Without the consent of Party A, it is not allowed to sublet. (transfer)

9. After the house renovated by Party B expires, the decoration shall be owned by Party A free of charge.

10 There is no guardrail on the stairs in Party A's courtyard, and there is a deep well landscape in the courtyard. If Party B's children play in it and go up and down the stairs, the safety accident shall be borne by Party B, and Party A shall not be held responsible.

Article 6 Rights and obligations of Party A

1, collect the contract fee and electricity fee on schedule.

2. Be responsible for transferring water and electricity for Party B, and Party B must pay the fee on time. If Party B refuses to pay the electricity fee when Party A collects it, Party A has the right to stop the power supply immediately.

3. Supervise Party B's use of the Contract House. If Party B is found to have damaged the Contract House and other properties or changed the structure of the Contract House, it has the right to stop and order it to be restored to its original state or pay compensation at a discount.

Article 7 Liability for breach of contract

During the contract period, if either party breaches the contract, it shall bear a penalty of 6,500 yuan to the other party.

Article 8 Others

1. A supplementary agreement shall be signed separately for matters not covered.

2. The future supplementary agreement has the same effect as this contract.

3. This contract shall take effect from the date of signing and paying the contract fee, and shall be terminated when the house contract expires.

4. This contract is made in duplicate, with each party holding one copy.

Signing parties:

Party A: Party B:

October 15th, 2002

Housing construction contract 5

Party A (lessor): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Lessor's representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B (the lessee): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Legal Representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Company address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

In order to protect the legitimate interests of both parties to the land lease contract, standardize the land management and the lessee's business behavior, Party A and Party B sign this contract on the principles of equality, voluntariness, fairness and compensation in accordance with the Land Management Law of the People's Republic of China, the Civil Code of People's Republic of China (PRC) and relevant laws, regulations and policies, and both parties shall abide by it.

Attorney's Letter: The Marriage Law, Inheritance Law, General Principles of Civil Law, Adoption Law, Guarantee Law, Contract Law, Property Law, Tort Liability Law and General Principles of Civil Law shall be repealed at the same time on _ _ _ _ _ _ _ _ _ _. (Delete)

Article 1 Location and area of lease

The cultivated land leased by Party A to Party B is located in _ _ _ _ _ _ _ _ _ * _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

East: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

West to: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _,

North to: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _,

South to: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

The specific area and location shall be subject to the attached drawings of the contract.

The attached drawings have been signed and confirmed by both parties.

Article 2 Use of cultivated land

Land use: During the lease period of cultivated land, Party B is free to choose ecological farming projects as its main business.

Article 3 Term of lease

The lease term is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ If it is necessary to renew the lease, Party A and Party B shall renegotiate the lease renewal.

Article 4 Lease fees and payment methods

(1) The rental fee for cultivated land is RMB per mu/year in the first year after the contract comes into effect.

Starting from the second year, it will increase by% every year.

In the first 1 year, the rental fee is * * * yuan per mu, that is, _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

The second year: the rental fee is _ _ _ _ _ _ yuan * * *: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

The third year: the rental fee is _ _ _ _ _ _ yuan * * * per mu/year: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

The fourth year: the rental fee is RMB per mu/year * * *: RMB per mu (in words: _ _ _ _ _ _).

Fifth year: the rental fee is RMB per mu/year * * *: RMB per mu (in words: _ _ _ _ _ _).

Sixth year: the rental fee is _ _ _ _ _ _ yuan/year * *: _ _ _ _ _ _ yuan/mu (in words: _ _ _ _ _ _ _ _).

Seventh year: the rental fee is _ _ _ _ _ yuan per mu/year * *: _ _ _ yuan per mu (in words: _ _ _ _ _ _ _).

Eighth year: the rental fee is _ _ _ _ _ _ _ yuan per mu/year * *: _ _ _ _ _ _ yuan per mu (in words: _ _ _ _ _ _).

Ninth year: the rental fee is _ _ _ _ _ _ yuan * * *: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Year 10: the lease fee is * * *: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

During the performance of this contract, Party B must be on 16 of the first month of each year (postponed in case of legal holidays).

(2) Pay the rental fee, water fee and electricity fee of this year and last month to Party A's financial account. After Party A collects the rent, it will issue a receipt. If Party B needs invoices, Party B will be responsible for paying taxes. Performance bond:

(3) Party B shall pay a performance bond of RMB 65,438+0,000,000.00 Yuan to Party A on the date of signing the contract. After the termination of this agreement, Party A will refund the deposit to Party B without interest within 65,438+05 days after the expenses payable by Party B are settled. However, if there is a dispute between Party B and Party A, the deposit can be used to offset the last rent. If the contract is terminated due to one of Party B's illegal agreements, Party A will not refund the deposit.

Article 5 Rights and obligations of Party A and Party B

(I) Rights and obligations of Party A

1. Party A owns the leased cultivated land and enables Party B to obtain the contracted use right and management right of the land.

2. Party A has the right to supervise the use of the cultivated land leased by Party B to ensure the rational use of the cultivated land according to the purposes agreed in the contract.

3. Party A has the right to take back the land not used by Party B according to the contract.

4. Party A has the right to stop Party B from seriously damaging cultivated land resources and other assets.

5. Party A has the right to charge Party B the rent and the water and electricity charges according to this contract, and Party A shall not increase the rent during the contract period.

6. Party A has the right to propose new lease standards and choose a new lessee at the expiration of the lease term.

7. Party A shall ensure that Party B's production and living water and electricity consumption are normal, and the price of water and electricity charged to Party B is% higher than that of villagers in the village, and ensure that the road leading to the leased land in the village is used free of charge, and compensate for the damage.

8. During the lease term, Party A shall not interfere with Party B's legal management right for any reason, including all income and expenditure on cultivated land and the use of legal temporary buildings and tree planting facilities.

9. During the performance of this contract, Party A shall not contract the cultivated land repeatedly. During the lease period, Party A shall be responsible for the settlement of farmland disputes arising from the contracted scope. If Party B suffers serious economic losses, Party A shall compensate it according to relevant state regulations. Party A must ensure that Party B will not be unreasonably disturbed during the contract period.

10. Provide Party B with other equal treatment for local villagers.

(II) Rights and obligations of Party B

1. Party B has the right to legally use and operate the contracted cultivated land according to the purpose and time limit stipulated in the contract.

2. Party B's management right and income right of contracted farmland are independent according to law, and no unit or individual may interfere. All creditor's rights and debts incurred shall be enjoyed and borne by Party B alone and have nothing to do with Party A. ..

3. Party B has the right to legally build temporary breeding and living facilities related to the purposes agreed in this contract on the contracted cultivated land, and Party A and its village do not charge any fees.

4. Party B has the right to carry out basic transformation of leased farmland during the lease term. If all the assets such as power grid and water conservancy facilities formed by transformation are invested by Party B, Party B has the right to dispose of them after the lease contract expires.

5. After the lease expires, under the same conditions, Party B has the priority to continue to lease the original leased farmland.

6. Party B shall pay the rent to Party A in full and on time as agreed in this contract, and has the right to refuse to pay any other non-state expenses except the rent stipulated in this contract.

7. Party B's project operation activities shall not pollute the water source of Party B's village, and shall not cause other ecological environment pollution that affects the villagers' lives.

8. Party B shall protect natural resources and make rational use of land.

9. After the lease contract ends, Party B shall be responsible for cleaning up the paddy field sundries and cultivating the cultivated land (restoring the normal cultivated land state). If Party B fails to ridge the cultivated land (restore the normal cultivated land status), Party B shall pay a ridging fee of RMB 0,000 per mu/kloc-0 (restore the normal cultivated land status) to Party A, and confiscate the performance bond.

Article 6 Subcontracting

Within the validity period of this contract, Party B may independently transfer the contracted land management right by subcontracting, transferring or leasing, provided that it does not violate the mandatory provisions of national laws and administrative regulations. All the proceeds from the transfer of the land contractual management right shall be enjoyed by Party B, and Party A shall not claim any rights in this regard. After subcontracting this contract, both parties shall still exercise their rights and undertake their obligations as agreed in the original contract; Party B and the third party shall exercise their rights and assume their obligations in accordance with the provisions of the subcontract. After subcontracting this contract, if the subcontract cannot be performed due to Party A's reasons, thus causing losses to the subcontractor, Party A shall bear corresponding responsibilities.

Article 7 Modification and rescission of the contract

1. Once this contract is signed, it is legally binding, and no unit or individual may change or terminate it at will. This contract can only be modified or dissolved after both parties sign a written agreement through consultation.

2. If Party A and Party B are unable to perform this contract due to force majeure, or this contract really needs to be modified or dissolved, this contract can be modified or dissolved according to legal procedures after negotiation between both parties, and the economic losses caused thereby shall be borne by both parties themselves or solved through negotiation.

3. If Party A repeatedly contracted the land or cut off power, water and road without authorization, which made Party B unable to operate, Party B has the right to terminate this contract, and Party A shall bear the liability for breach of contract.

4. If Party B fails to pay the rental fee in full and on time, and Party A refuses to pay after being urged by Party A, Party A has the right to terminate this contract, and Party B shall bear the liability for breach of contract.

Article 8 Liability for breach of contract

1. During the performance of this contract, any party who violates the above provisions of this contract shall be regarded as a breach of contract.

2. If this contract is terminated due to Party A's breach of contract, Party A shall pay the annual rent to Party B as liquidated damages and return the performance bond paid by Party B; Where the Contract is terminated due to Party B's breach of contract, Party A will not refund the contract fee and performance bond fee to Party B and terminate the Contract. If the contract is terminated due to the fault of both parties, they shall bear corresponding liabilities for breach of contract.

Article 9 Measures for Settlement of Contract Disputes

In case of any dispute during the performance of the contract, both parties to the dispute shall settle it through consultation. If negotiation fails, it may apply to the higher authorities for mediation or bring a lawsuit directly to the local people's court.

Article 10 the contract comes into effect

This contract shall come into effect after being signed and sealed by both parties.

Article 11 Other matters

1. Matters not covered in this contract can be used as a supplementary agreement after both parties agree, and the supplementary agreement is the same as this contract.

Have the same legal effect.

2. This contract is made in duplicate, with each party holding one copy.

Lessor: (hereinafter referred to as Party A) _ _ _ _ _ _

Representative: _ _ _ _ _ _ _ _ _

Contact mobile phone: _ _ _ _ _ _ _ _ _

Party A (signature): _ _ _ _ _ _ _ _ _ _ _

Lessee: (hereinafter referred to as Party B) _ _ _ _ _ _

Representative: _ _ _ _ _ _ _ _ _

Contact mobile phone: _ _ _ _ _ _ _ _ _

Party B (signature): _ _ _ _ _ _ _ _ _ _ _

Signing time: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Five related clauses in housing construction contract:

★ 3 copies of individual housing construction contract.

★ 5 construction contract templates.

★ 3 copies of model clauses of house construction contract.

★ 3 housing construction contracts

★ 3 copies of model clauses of house construction contract.

★ The latest model of housing construction contract

★ 202 1 residential house decoration agreement 5 contracts.

★ 5 copies of model contract for rural self-built houses.

★ 5 Model contract for private residential projects.

★ 3 Model housing construction contract.