Article 5 of the 2022 model contract for individual rural self-built houses.

The conclusion and performance of a contract also belong to human behavior, which is a relatively formal behavior, so it should have a certain specific purpose. Therefore, for a specific contract party, its contract purpose is certain. Next, I'll sort out the model contract for individual rural self-built houses in 2022. I hope you like it!

Individual rural self-built house contract 2022 model essay 1

Seller (hereinafter referred to as Party A): _ _ _ _ _ _ (myself) (legal representative) Name: _ _ _ _ _ _ _ _

Nationality: _ _ _ _ _ _ Resident ID number: _ _ _ _ _ _ Address: _ _ _ _ _ _ Tel: _ _ _ _ _ _ _ Postal code: _ _ _ _ _ _ _ _

Buyer (hereinafter referred to as Party B): _ _ _ _ _ _ (himself) (legal representative) Name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Nationality: _ _ _ _ _ _ Resident ID number: _ _ _ _ _ _ Address: _ _ _ _ _ _ Tel: _ _ _ _ _ _ _ Postal code: _ _ _ _ _ _ _ _

Through negotiation between Party A and Party B, and with the consent of the land owner, the following contract terms are reached:

Article 1 Basic information of the house

Since Party A's three daughters are all working outside the home, and now Party A is also raising fish on its own land for a living, the old house of Zhangjia Group has been abandoned. Now Party A voluntarily sells the house courtyard (including a main house, a kitchen and a pigsty) and some accessories located in _ _ _ _ _ _ _ _ _ _ _ _, which was built in 20 years. And its structure is civil, with a construction area of _ _ _ _ _ _ _ _ _ square meters (of which the actual construction area is _ _ _ _ _ _ _ _ _), and the purpose of the house is _ _ _ _ _ _ _ _ _ _ _ _ _ _; See Annex I to the Contract for the floor plan of the house and Annex II for the floor plan of the land attached to the house. (house ownership certificate, land use right certificate number) (real estate certificate number) is _ _ _ _ _. The specific location of the yard is:

East neighbor:

South neighbor:

West neighbor:

North neighbor:

The registered length is: m, the width is m and the area is * * * square meters.

All relevant accessories of the hospital are transferred at the same time, including: a tea garden at the back of the house at two o'clock, all fruit trees in front of and behind the house, an old pool and its water source, an acre of vegetable field at the back of the house at five o'clock and a piece of cultivated land. Party B's family is allowed to be buried in Linquan Mountain of Party A's house after death, and the land is buried free of charge.

Article 2 Special Agreement on Housing Area

The area agreed in Article 1 of this Contract is (temporarily measured by Party A) (indicated on the original property ownership certificate) (actually measured by the real estate property registration authority). If there is any difference between the temporarily measured area or the area marked on the original property certificate (hereinafter referred to as the temporarily measured area) and the area actually measured by the real estate property registration authority, the area actually measured by the real estate property registration authority (hereinafter referred to as the actual area) shall prevail.

When the house is delivered, the house price will remain unchanged when the difference between the actual area and the temporarily measured area does not exceed 10% of the temporarily measured area. When the difference between the actual area and the temporarily measured area exceeds 50% of the temporarily measured area, both parties agree to handle it through negotiation.

Article 3 Nature of land use right

The corresponding acquisition method of the land use right of the house is _ _ _ _ _ _ _ _ _ _ _; The term of land use right is from year month day to year month day. The approval number of the real estate transfer that obtains the land use right by allocation is _ _ _ _ _ _ _ _ _ _; After the house is bought and sold, according to the relevant regulations, Party B does not need to go through the formalities of land use right transfer.

Article 4 Price

Both parties agree that the total price of the above-mentioned real estate and ancillary buildings is RMB in words.

That is, the numerical RMB. Where (in figures:) is the actual house price, and (in figures:) is used for the plot (area of square meters) after the purchase of _ _ _ _ house as the road. (in figures:) used to purchase _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A shall deliver the house to Party B a few days ago; At that time, the property will be free of any guarantee, mortgage and property defects, and no one will rent or use it; No debt, such as telephone, utilities, cable TV, etc.

Article 5 Payment Terms

Party B shall pay Party A a deposit of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 6 Time limit for delivery

Within 30 days from the effective date of this contract, Party A shall hand over the property right certificate of the house to Party B.. And shall pay the house to Party B within _ _ _ _ _ _ _ _ years.

Article 7 Party B's liability for breach of contract for overdue payment

If Party B fails to make the payment according to the time stipulated in Article 4 of this contract, Party A has the right to pursue the default interest on the overdue payables of Party B. The monthly interest is calculated at _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ At that time, Party A has the right to pursue Party B's liability for breach of contract according to the following _ _ _ _ _ _ _ _.

1. When this contract is terminated, Party B shall pay Party A 5% of the accumulated payables as liquidated damages. When the actual economic loss of Party A exceeds the liquidated damages paid by Party B, the difference between the actual economic loss and the liquidated damages shall be compensated by Party B according to the facts.

2. Party B shall pay liquidated damages to Party A at the rate of 5% of accumulated payables, and continue to perform the contract.

Article 8 Party A's liability for breach of contract for overdue delivery.

Except for irresistible natural disasters and other special circumstances, if Party A fails to deliver the house to Party B for use within the time limit specified in Article 5 of this contract, Party B has the right to claim penalty from Party A according to the paid house price. From the date of the month, the monthly interest is calculated at the date of the month, and the monthly interest is calculated at the interest rate of _ _ _ _ _ _ _. If the delay exceeds _ _ _ _ _ months, Party A shall be deemed to have failed to perform this contract, and Party B shall have the right to hold Party A liable for breach of contract.

1. If the contract is terminated, Party A shall pay Party B 5% of the accumulated payment. When the actual economic loss of Party B exceeds the liquidated damages paid by Party A, the difference between the actual economic loss and the liquidated damages shall be compensated by Party A according to the facts.

2. Party A shall pay 5% of the accumulated payment to Party B and continue to perform the contract.

Article 9 Property Rights Registration Agreement

Party A guarantees that the property is legal, the ownership is clear and the land use right is legal. And obtained the unanimous consent of all * * *. If Party B can't use the house normally due to property rights, use rights or other property rights, Party A is willing to pay Party B all the leasing, decoration, construction, decoration and land appreciation of the house.

After the Contract comes into effect, Party A has the obligation to cooperate with Party B to handle the transfer of relevant property certificates. If it is really impossible to handle the transfer of property rights due to government reasons, Party A shall submit relevant certificates to Party B for preservation. In case of government land acquisition and demolition, all the demolition benefits of the courtyard (including demolition compensation, relocated houses, etc.). ) owned by Party B. ..

Article 10 Party A guarantees that there is no property right dispute during the transaction, and all mortgages, mortgage debts, taxes and rents shall be settled by Party A before the transaction. If there are any matters not mentioned above after the transaction, Party A shall bear all the responsibilities.

Article 11 For matters not covered in this contract, Party A and Party B shall negotiate separately and sign a supplementary agreement.

Article 12 The annexes to this contract are an integral part of this contract. In this contract and its annexes, the words filled in the blank part have the same effect as the printed words. Matters not covered in this contract, its annexes and supplementary agreements shall be implemented in accordance with relevant laws, regulations and policies of People's Republic of China (PRC).

Article 13 Any dispute arising from the performance of this contract shall be settled by both parties through consultation. If negotiation fails, Party A and Party B agree to arbitration by the village committee.

Article 14 This contract (signed by both parties) shall come into effect as of the date of signing.

Article 15. This contract and the attached schedule * * _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A (signature and seal):

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Signed on _ _ _ _ _ _ _ _

Party B (signature and seal):

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Signed on _ _ _ _ _ _ _ _

Individual rural self-built house contract 2022 model essay 2

Seller (Party A):

ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Buyer (Party B): _ _ _ _ _ _ _ _ _ _ _

ID number: _ _ _ _ _ _ _

According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, in order to clarify the rights and obligations of both parties, on the basis of equality, voluntariness and consensus, Party A and Party B have reached the following agreement on the purchase of the house by Party B from Party A:

I. Location and area of the house:

The house is located at:No. Hefuguo State Administration Bureau (building area), and the land certificate number is _ _ _ _ _ _ _. Now Party A sells the second floor of the completed house to Party B, with a construction area of _ _ _ _ _ _ _ _ _ _ _ _ square meters, and the specific area is subject to the property ownership certificate. _ _ _ _ _ _ _ Yuan only (￥ _ _ _ _ _ _ _ _ _). Party A shall deliver the house to Party B in _ _ _ _ _ _ _ _ _ (RMB: _ _ _ _ _ _ _).

Two. General situation of the house, pricing and payment method:

The house has been completely renovated by Party A and can be occupied. When the total transaction price is RMB yuan (that is, when signing this contract), Party B shall pay the total house price in full.

Three. Responsibilities and rights of Party A

1. Party A guarantees that the house sold is legal and there is no property right dispute during the transaction. About mortgage, mortgage debt, tax, etc. Party A has settled all matters before the transaction. If there are any matters not covered after the transaction, Party A shall bear all the responsibilities.

2. After this contract is signed, Party A shall not enter into a sales contract with others for this house.

3. Party A promises to handle the real estate license within _ _ _ _ _ _ _ months after the signing of this contract, and all expenses for handling the real estate license shall be borne by Party A. If the real estate license is not handled after 24 months due to Party A's reasons, Party A shall compensate Party B. ..

Four. Responsibilities and rights of Party B

1. After the signing of this contract, Party B enjoys the ownership of the house, and Party A shall not affect Party B's ownership of the house in any way or for any reason.

2. If Party B needs to redecorate the house, it shall not affect the structural safety of the house itself.

Verb (abbreviation of verb) Matters not covered in this contract shall be implemented in accordance with relevant laws, regulations and policies of People's Republic of China (PRC).

6. Any dispute arising from the performance of this contract shall be settled by both parties through consultation. If negotiation fails, both parties agree to arbitrate by peace county Arbitration Commission.

VII. This contract and its annex Land Use Certificate are made in duplicate, one for each party, and shall come into effect as of the date of signature (signature) by both parties, with the same legal effect.

Party A: _ _ _ _ _ _ _ _ _

Date: _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _

References: _ _ _ _ _ _ _ _

Date: _ _ _ _ _ _

Individual rural self-built house contract 2022 model essay 3

Party A:

Party B:

Party A and Party B have reached the following transfer agreement on the transfer of the right to use the house through voluntary, equal and friendly negotiation:

I. Location and area of the house

Party A transfers the house located in _ _ _ _ _ to Party B with the registered area of *** 150.4 m2. The specific location is from east to south to west to north. The right to use the above-mentioned house and ancillary facilities includes: all building facilities and water and electricity accounts of the house where Party A is currently located. Party B shall enjoy it for life.

Second, ensure that the procedures of this house are true, the source is legal, the ownership is clear, and the boundaries are clear. In case of ownership or debt disputes related to Party A, Party A shall be responsible, and Party A shall bear all economic losses caused to Party B therefrom. ..

Third, the transfer amount.

The transfer price of this parcel is RMB _ _ _ _ _ _ _, in words: _ _ _ _ _ _ _.

Four. Payment method and time limit

Party B shall pay RMB 20,000.00 Yuan in advance to Party A, and the balance shall be delivered to Party B after obtaining the house use right certificate and relevant procedures.

Verb (abbreviation of verb): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Sixth, the ownership of real estate.

1. The house on the house is built by Party B at its own expense, and the property right belongs to Party B. ..

2. The construction procedures shall be handled by Party A, and the expenses shall be borne by Party B. ..

3. After the house is completed, Party A shall unconditionally cooperate with Party B to handle the land certificate and real estate license under Party B's name, and the relevant expenses shall be borne by Party B. ..

Seven. responsibility for breach of contract

After the signing of this agreement, neither party can go back on its word.

If Party A reneges on its promise, Party A shall return to Party B the full amount of _ _ _ _ _ _ _ _ _ _ _.

VIII. Under the premise of legal policies, Party A shall unconditionally cooperate with Party B to handle the house use certificate and related procedures in the name of Party B, and all related expenses involved shall be borne by Party B. If Party A violates this agreement and fails to transfer or deliver the house without any reason, Party A shall pay Party B a penalty of120,000 yuan.

Nine. This agreement is made in duplicate, one for each party. This contract shall come into effect after being signed by both parties. Matters not covered shall be settled by both parties through consultation.

Party A:

ID number:

Date, year and month

Party B:

ID number:

Date, year and month

Individual rural self-built house contract 2022 model essay 4

Seller (Party A):

Buyer (Party B): _

___________

Property location:

Signing place:

Date of signature: 20__ _

Rural self-built house sales contract

Seller (Party A): _ _ _ _ _ _ ID number: (property owner) _ _ _ _ _ ID number. : (property owner) _ _ _ _ _ ID number:

The above-mentioned _ _ _ _ _ person is the * * * owner of the house mentioned in this contract. The Seller and the Owner are hereinafter referred to as Party A..

Buyer (Party B): _ _ _ _ (hereinafter referred to as Party B) ID number:

On the basis of equality, voluntariness and consensus, Party A and Party B conclude the following terms of this contract for compliance.

Rule number one. Basic information of the house:

Party A voluntarily places its village certificate house in _ _ _ _ _ _ _ _ _ _ _

Article 2. Interior facilities and equipment of the house: including _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 3. When this contract is signed, neither Party A nor Party B has the conditions for transfer. When the transfer conditions are ripe, Party A shall fully assist Party B to handle the house property right confirmation formalities free of charge.

Article 4. Party A guarantees that there is no property right dispute, mortgage or guarantee and other rights defects in the house.

Article 5 Time and Method of Payment

Party B shall pay the house price of RMB _ _ _ _ _ _ _ _.

Pay RMB Yuan only to Party A in one lump sum.

Article 6 Commitments, Rights and Obligations of Party A

1. Party A guarantees that there are no quality and technical problems endangering the living safety in its house. If the house sold by Party A has quality problems that affect Party B's right to live, Party A shall bear all the responsibilities and compensate Party B for the losses.

2. Party A guarantees and promises to have the right to use the above-mentioned house and land (villagers' homestead), and there is no lease. All parties of Party A have no objection to the disposal of the appraised object. In the sale of houses and land, there is no preemptive right holder, and there are no other rights such as mortgage rights in houses and land, and the right to dispose of houses is not restricted. After the transaction, if any of the above matters occur due to the ownership problem, Party A shall bear the responsibility, and Party B shall not bear any responsibility.

3. After the signing of this contract, Party A will transfer the right to use, the right to income, the right to lease, the right to guarantee, the right to mortgage, the right to sell and the right to occupy the house to Party B..

Article 7 After the signing of this contract, Party A guarantees that Party B enjoys the same original right of residence as Party A. Party A shall not sign the ownership transfer contract with others.

Article 8 Transfer of houses and land

1. At the time of signing this contract, the house was self-built in rural areas, and it does not meet the transfer conditions temporarily. However, this contract is an agreement reached voluntarily by both parties on the basis of equal consultation and does not violate relevant laws and regulations.

2. Both parties agree that when the national policy allows the transfer in the future, Party A shall hand over the house ownership certificate such as the real estate license to Party B for safekeeping, and handle the advance notice registration formalities on the day when it is obtained. If it cannot be delivered to Party B for other reasonable reasons, and it is difficult to handle the advance notice registration on the same day, it shall also notify Party B on the same day and negotiate with Party B on the specific delivery date. ..

3. Party A shall, within three working days after obtaining the real estate license and other relevant ownership certificates, assist Party B to handle the house and land transfer formalities free of charge. Party A shall make every effort to assist Party B to handle the house property right formalities free of charge and unconditionally.

Article 9 Special Agreement

1. House demolition: After the signing of this contract, if the house is demolished by the government, Party A agrees that Party B has full authority to handle the house and land demolition procedures, and all the compensation and resettlement proceeds from the demolition shall be owned by Party B, and Party A shall not interfere. If Party A needs to cooperate in the process of demolition, Party A shall cooperate for free.

Second, about the second sale of real estate:

1. After the signing of this contract, Party B has the right to resell the house to others, and all the sales amount belongs to Party B, and Party A shall not interfere.

2. The rights and interests owned by Party B in this contract also belong to the new buyer, and Party A needs to actively cooperate.

Three. About the recovery of real estate:

As the house belongs to the rural self-built house, both parties have not gone through the formalities of property right transfer registration. After the transaction is completed, if Party A requests to repossess the house at any time, Party A agrees to pay Party B three times the appraised market price of the house at the time of repossession.

Article 10 Liability for breach of contract

1. If Party B fails to pay the house payment to Party A within the agreed time limit, and it is overdue for three months, Party A has the right to terminate this contract.

Chapter III: Transfer Agreement of Villagers' Self-built Houses

Agreement on transfer of villagers' self-built houses

Both parties to the contract:

Transferor (hereinafter referred to as Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party B): _ _ _ _ _ _ _ _ _ _ _ _.

Article 1: Location and nature of the leased land:

Party A's _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. (Attached with photos and the attachment of the homestead plan signed by both parties)

Article 2: Land transfer price and payment method

Party A and Party B * * * agree that the transfer price of the homestead is in figures: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 3: Rights and obligations of Party A and Party B:

1. After the signature of Party A, before receiving the payment for Party B's homestead, Party A shall provide Party B with the land title certificate, and ensure that the homestead is free from property rights disputes and financial disputes. If there is any dispute before and after the handover, Party A shall bear all the responsibilities.

2. When Party B handles the house property right and various formalities in the process of land use and construction,

Party A shall actively cooperate with Party B's work and provide assistance to Party B without regret or any conditions. After the contract comes into effect, all the property rights of the homestead, including the houses under construction in the future, such as all the money collected by the state, any unit or individual, shall be owned by Party B, which has nothing to do with Party A. Party A must cooperate and support in handling the land use and house property certificate in the future, and the house property rights shall be owned by Party B. ..

3. In the process of construction, if there are disputes such as land ownership, inability to handle legal building procedures, land use certificate, real estate license, adjacent disputes, and government departments preventing building due to Party A's reasons, Party A shall actively cooperate with mediation to ensure the smooth completion of building the homestead. The expenses incurred during this period shall be borne by Party A. ..

4. After this contract comes into effect from the date of signing, the ownership of the house and land shall be owned by Party B. ..

5. Ownership of the house. In the future, if the government department allows private transfer, Party A shall actively cooperate with Party B to handle the transfer formalities without any additional conditions (note: Party B shall bear the expenses when handling the transfer formalities).

6. After this contract comes into effect, Party A shall ensure the smooth completion of the self-built house. If the government department delays or stops work due to incomplete construction procedures, and the Law Enforcement Bureau stops the construction, Party A shall refund the self-built house funds of the homestead according to the actual situation.

7. Party A's original tap water and electricity contract shall be transferred to Party B at the same time after it takes effect.

Article 4: Liability of both parties for breach of contract

After this contract is signed by both parties, Party A and Party B shall not go back on their words or break the contract.

After the contract comes into effect, if Party A fails to deliver the homestead to Party B for use on time as stipulated in the contract, Party B has the right to hold Party A liable for breach of contract, and the penalty is RMB 1 1,000 per day. After one month, it will be regarded as a serious breach of contract, and Party A will pay Party B ten times the total house price of the homestead and the house under construction. Party A shall not refuse to pay liquidated damages to Party B for any reason.

Article 5: Settlement of disputes

In case of any dispute between Party A and Party B during the performance of the contract, it shall be settled by the arbitrator first. If mediation fails, it shall be settled through litigation in the local people's court.

Article 6: Entry into force of the contract

The signing date of this contract is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

The place of signing this contract is: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 7: This contract is made in quadruplicate, one for each party and witness.

Article 8: Signature of the parties and witnesses (by handprint)

Party A (Seller) (name: husband and wife): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Contact number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ : _ _ _ _ _ _ _ _ _ _ _ _ Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 9: The floor plan, photos, copies of ID cards and original vouchers shall be attached to this contract and have legal effect.

Individual rural self-built house contract 2022 model essay 5

Party A:

Party B:

Party A's house under construction has two floors, one floor is about square meters, and the other floor is about square meters, which is contracted by Party B. Based on the principles of equality, mutual benefit, honesty and credibility, both parties agree to sign this agreement through consultation, so as to abide by it jointly:

First, the contracting method.

Take the way of contracting without contracted materials.

Party A shall provide materials needed for the building, including: red bricks, river sand, stones, lime, cement, steel, water pipes, sewer pipes, nails, wires, water and electricity, etc.

Party B shall provide labor services, construction technology, construction tools and all production and living appliances.

Second, the construction project

Party B shall carry out the construction according to the design drawings or the requirements put forward by Party A. The buildings of Party A's main building project include walls, beams, columns, stairs, floors, formwork installation, formwork removal, steel bars, cast-in-place concrete and concrete cushion for the ground and front steps; Paint the interior decoration, paste the front exterior wall tiles, brush cement mortar along the rear exterior wall, paste the bathroom floor and wall tiles, and install porcelain pots, sewer pipes and downspouts; The top layer shall be polished with cement slurry, and at the same time, it shall be well treated for seepage prevention and impermeability.

Third, the contract price

RMB in words per square meter: _ _ Yuan, and the construction area is calculated according to each external wall. The construction scope includes all the walls that need cement mortar plastering.

Four. mode of payment

After the contract is signed, the tools and personnel are in place, 30% in advance, 50% when the first floor is bricked and compacted, 8000 yuan when the second floor and roof are completed, and 90% when the project is completed. 65,438+00% shall be reserved as quality deposit. If there is no quality problem within one year after completion, the final payment shall be paid.

Verb (abbreviation for verb) The responsibility of both parties.

Party A is responsible for the timely supply of water and electricity, the timely entry of raw materials and the daily lunch.

Party B must ensure the quality and progress of the project, carry out the construction according to the design drawings and Party A's requirements, save materials, take good care of them and not lose them.

Six, quality requirements

Party B shall organize the construction in accordance with the national housing quality standards and requirements. If it is unqualified, Party B shall be responsible for rework, and the rework fee shall be borne by Party B or deducted from Party B's project payment by Party A..

Seven, pay attention to safety

Labor protection measures, construction protection measures in place, safe construction. If Party B's construction personnel suffer work-related injuries due to their own reasons or Party B's inadequate safety protection measures, or others are injured due to construction, Party B shall be responsible for everything, and Party A shall not bear any responsibilities and expenses. Civilized construction, pay attention to professional ethics, pay attention to cleanliness.

Eight, the time limit for a project requirements

The main project duration is 75 (calendar days). Since the date of signing this contract, Party B must complete the main project ahead of schedule, which will be postponed due to the weather. Party B shall not delay the completion time of Party A's building for various reasons. If Party B needs materials, Party B shall submit the plan to Party A in advance for timely preparation.

Nine, the later maintenance

The maintenance expenses arising from Party B's quality problems shall be borne by Party B, and the relevant compensation and responsibilities arising therefrom shall be borne by Party B..

X. others

Other matters not covered shall be settled by both parties through consultation, and shall be implemented in strict accordance with national and local standards.

This contract is made in duplicate, one for each party, and shall come into effect as of the date of signature.

Signature (seal) of Party A:

Signature (seal) of Party B:

Two. Party A, Model Contract of Rural Housing Project:

Party B:

Form of contract:

1. Party B is responsible for contracting 1#-3# multi-storey residential building's indoor and outdoor decoration works, painting and painting works, and contracting materials marked in drawings, and others are contractors.

2. When Party B enters the site, Party A provides accommodation, and the living expenses shall be borne by Party B (living and water and electricity expenses shall be borne by Party B).

3. Party A shall provide mixers, water pipes and trolleys (trolleys shall be maintained by Party B).

Contract price:

1#-3# renovation project of multi-storey residential building, painting and oiling project (contracting work and materials) shall be contracted by Party A to Party B at the price of 56 yuan/m2 (construction area).

Contract content:

Party B is responsible for the decoration construction works (excluding waterproof works) of the drawing design of 1#-3# multi-storey residential building, such as roofing works, plastering works, painting works, floor works, outdoor aprons and all insulation parts.

Quality requirements and acceptance criteria.

This project is designed for intermediate plastering, and the quality standard is qualified. The specific requirements are:

1, the allowable deviation of verticality of the positive surface is 3 mm, the flatness is 2 mm, and the angle of yin and yang is 2 mm. ..

2, Yang surface look and feel level off, smooth, consistent color, no empty drum, no obvious if, and is responsible for the indoor ceiling height, plaster lining with large error.

3. The angle of Yin and Yang should be vertical, the lines should be straight, the upper and lower floors of the outer balcony and window sill should be straight, the balcony board and bay window board should be of the same thickness, and the flashing should be done well.

4, paint and pure engineering surface should be smooth, smooth, consistent color, no sagging, peeling rust and other phenomena, and completes the finished product protection.

5. If the above requirements fail to meet the qualified requirements, economic penalties will be imposed on rework and material waste.

Completion time:

Party B shall complete all contract work items within 30 days from the date of entry and meet the acceptance criteria. If it is not completed within the time limit, it will be fined RMB for each day of delay (including rainy days).

Payment method:

1. Party A shall pay the project progress payment to Party B according to% of the completed project amount (it must pass the acceptance).

2. Other payments shall be paid within three months after the completion and acceptance of all projects contracted by Party B..

Maintenance, use and material saving of tools and equipment;

1. Party B must use the equipment and tools on the construction site reasonably and safely.

2. Party B shall regularly maintain and repair the on-site equipment and tools.

3. In the process of construction, Party B shall pay attention to saving materials, reasonably mixing materials, and use up materials on the same day.

4, the ground mortar increases with the increasing use, it is forbidden to ground ash as garbage landfill, if found a fine 200 yuan.

5. Party B shall carry out the work of "three clean-ups and six good practices" and clean up the working face at any time.

Civilized construction and safe production:

1. When Party B comes into the site, it must carry out the construction in strict accordance with the technical operation procedures for on-site safety production.

2, the correct and safe use of all electrical equipment and temporary electricity in the construction site, must wear a helmet.

3, workers are not allowed to wear slippers to work, no bare arms, no defecation anywhere.

4, workers should be civilized construction, no swearing, swearing, no fighting, if found a punishment 500 yuan.

5. Workers should go to work in strict accordance with the operating procedures. In case of casualty, all economic expenses and losses shall be borne by Party B. ..

This agreement is made in duplicate, one for each party.

Party A: Party B:

Year, month, sun, moon, sun.

Article 5 of the Model Clauses of Rural Individual Self-built Housing Contract in 2022;

★ Individual construction contract template

★ 5 Model contract for private residential projects.

★ 5 reference models for the sale contract of rural houses in 2022.

★ 6 concise versions of individual housing sales contract model

★ 2022 Template for Construction Contract of Conventional Construction Project

★ How to write the application for self-built houses in rural areas in 2022?

★ Application conditions for rural self-built houses in Hubei Province 2022

★ Model Contract for Anticorrosion Project in 2022

★ 5 copies of garbage removal contract model.

★ Sample of individual building application in rural areas